2024 Renovation Contract Sample Part 1
The employer (hereinafter referred to as Party A) :(Owner) and contact information:
Contractor (hereinafter referred to as Party B): Contact number of the person in charge of the construction team
Company Address: Company Contact Number:
Company Seal:
Article 1 Project Overview
1. Party A's decorated housing is legally resided. 2. Decoration construction site:
3. Construction scope: bedroom, living room, dining room, kitchen, bathroom, balcony, with an area of square meters. 4. Decoration construction content: the water, electricity, and weak current renovation project of Party A's housing, the wall transformation, the production of window and door covers, the paving of floor tiles and tiles, the laying of ground keels and raw floors, the installation of ceilings, top and wall coatings, kitchen utensils, sanitary ware, lamps, doors and other facilities, storage rooms, handling projects and other agreements between the two parties, as well as all the projects that should be included in the residential interior decoration project.
5. The contracting method is Party B's contracted labor and part of the materials.
6. Total price: ¥ yuan, capitalized (RMB): Where:
Material cost: ¥ yuan. Labor cost: ¥ RMB. Management fee: ¥ RMB. Design fee: ¥ RMB. Garbage removal fee: ¥ RMB. Tax: ¥ RMB. Material handling fee: ¥ RMB. Other fees: ¥ yuan.
The above total price is determined according to Party B's on-site inspection of Party A's house and a preliminary understanding of the required completion of the project, which is the closed price, including all the labor in the decoration project undertaken by Party B and all other auxiliary materials except Annex III "Party A's Self-purchased Material List".
If Party A changes the construction content and changes the materials, the additional material costs will be calculated separately.
7. Construction period: from the start of the year, to the completion of the year, the construction period, the construction period.
Article 2 Agreement on the Responsibilities of the Parties 1. Party A's Responsibilities:
(1) Party A shall make on-site disclosure to Party B one day before the start of construction. Provide Party B with the necessary conditions such as water and electricity required for construction, and explain the precautions for use.
(2) Do a good job in the coordination of the temporary use of common parts in the construction and the impact on neighborhood relations.
(3) Provide self-purchased materials on time according to the needs provided by Party B.
2. Responsibilities of Party B:
(1) Participate in the on-site disclosure of the construction design plan organized by Party A, and be responsible for conveying Party A's design plan and construction effect to specific construction personnel.
(2) During the renovation period, Party B fully undertakes the management and construction responsibilities of the person in charge of the construction engineering team, and is responsible for the quality, construction period and construction site safety of the decoration project. Party B fully undertakes the responsibilities of contacting Party A, ensuring the quality of the materials provided, proposing material requirements to Party A, and managing the quality of decoration construction and construction personnel on site.
(3) The person in charge of Party B is responsible for organizing the decoration personnel to participate in the decoration project defined in this contract, and is responsible for the personal safety of the construction personnel. During the construction process of a single project, Party B shall not replace the construction personnel without the permission of Party A; The replacement of construction personnel with the permission of Party A must be on the premise of ensuring the quality of construction; If Party A has doubts about the construction level of Party B's decoration personnel, Party B shall replace it unconditionally.
Article 3 Agreement on the supply of materials
1. Materials provided by Party A: (see Annex III "List of Materials Purchased by Party A").
Party A is responsible for the procurement and supply of materials and equipment, which shall meet the design requirements of qualified products, and shall be supplied to the site on time, and Party A and Party B shall go through the handover procedures. If Party B finds that the materials and equipment provided by Party A have quality problems or specifications are different, it shall be submitted to Party A in a timely manner, and Party A still indicates that it will use it, and Party A shall bear the responsibility for the project loss and delay in the construction period. After the materials supplied by Party A arrive at the site on time, Party B shall be responsible for keeping and organizing the construction after the joint acceptance of Party A and Party B, and Party B shall be responsible for compensation for the loss of materials caused by improper storage or improper construction technology.
2. The decoration materials and equipment purchased and supplied by Party A shall be used for the residential decoration specified in this contract, and Party B shall not be diverted for other purposes without the consent of Party A. If Party B violates this provision, it shall compensate Party A twice the price of the misappropriated materials and equipment. 3. Party B provides construction tools; Materials provided by Party B: (see Annex 2 "Quotation of Contracted Materials").
Party B shall supply materials and equipment in strict accordance with the brand, specification, model and other contents and design and construction requirements specified in Annex II "Quotation of Contracted Materials"; Materials without designated brands should meet the quality and environmental protection standards stipulated by the state and industry; Party A shall go to the site for acceptance, and shall prohibit the use if it does not meet the design, construction requirements, quality, environmental protection or specifications are different. If it has been used, Party B shall be responsible for the loss caused by the project.
4. All materials contracted by Party B should be carried into the house by themselves. Party A purchases its own materials, and promises to do its best to require the decoration material supplier to deliver the decoration materials to Party A's house under the premise of free of charge. However, if the material supplier insists on only being responsible for delivering the goods to the downstairs of Party A's residence, Party B shall be responsible for moving such decoration materials to the house.
5. In order to ensure the normal progress of the project, Party B must submit a list of materials to Party A in writing at least one week in advance for the next process, so that Party A can purchase materials on the weekend. Party A shall provide the materials required by Party B on time. Party B must also provide approximately accurate (+/- 10%) quantities of the required materials. The transportation costs for the re-purchase of materials or the return of materials due to the error of Party B's material estimation is greater than 10% will be borne by Party B, or Party B will be responsible for transporting the materials back to the supplier.
Article 4 on the quality and acceptance of the project agreement
1. The project implements DBJ08-62-97 "Technical Regulations for Residential Building Decoration Engineering", DB31/T30-1999 "Residential Decoration Acceptance Standards" and other local standards and quality assessment acceptance standards formulated by the municipal construction administrative departments.
2. The design and construction plan of this project shall be provided by Party A. Party B is responsible for the construction in accordance with the relevant industry regulations and with reference to the construction technology agreed in Annex VI "Construction Technology List".
3. Regarding the construction process, the two parties shall make the following agreements:
1). Bathrooms and kitchens should be waterproofed and tested for 12 hours 2). The sanitary ware is firmly fixed and the pipe interface is tight.
3). The line must be able to twitch after passing through the pipe.
4). The fir floor is laid at a 45 degree angle to the keel and fixed with wood screws. 5). Wall latex paint, one bottom and two sides 6). Door casing and kicking line, one bottom and three sides
7). Door, one bottom and three sides
4. If the quality of the materials and equipment provided by Party A is unqualified and the quality of the project is affected, the rework cost shall be borne by Party A, and the construction period will be extended. 5. If the quality accident is caused by Party B, the rework fee and material loss shall be borne by Party B. During the construction period and the warranty period, if the property loss of the surrounding neighbors is caused by the construction quality problems, Party B shall be responsible for repairing and compensating;
6. During the construction process, Party A proposes design modification opinions and addition or deletion of the project, and must contact Party B in advance before the construction of the project can be carried out.
7. If part of the process is installed free of charge by Party A's material supplier or arranged by Party A to be installed by other units, Party A shall arrange the time in advance and notify Party B, and Party B shall cooperate and avoid the delay of the overall construction period.
8. Project acceptance: Both parties A and B shall go through the inspection and acceptance procedures of concealed projects and intermediate projects in a timely manner. For each node of the project, Party B shall notify Party A two days in advance for acceptance. Without the written confirmation of Party A in the Annex IV "Project Quality Acceptance Form", Party B shall not carry out the next stage of project construction. (Refer to Shanghai Local Standard DB31/T30-1999 "Residential Decoration Acceptance Standards" and Annex VI "Construction Technology List"). If Party A cannot organize the acceptance within the specified time, it shall notify Party B in time and set another acceptance date. If it passes the completion acceptance, Party A shall recognize the original completion date.
9. Completion of the project: Party B shall notify Party A of the acceptance two days in advance, and Party A shall organize the acceptance within three days of receiving the notice, and go through the acceptance confirmation procedures in writing (see Annex IV "Project Quality Acceptance Form"). If Party A cannot organize the acceptance within the specified time, it shall notify Party B in time and set another acceptance date. If it passes the completion acceptance, Party A shall recognize the original completion date.
10. The warranty period of the project is one year, calculated from the date of completion acceptance and confirmation. During the warranty period, due to the quality problems caused by Party B's improper construction and the unqualified quality of the materials provided by Party B, Party B will unconditionally carry out maintenance and bear the corresponding material costs. If Party A suffers losses due to the above reasons, Party B shall bear the corresponding liability for compensation; During the warranty period, if Party A is damaged due to improper use, until it cannot be used normally, Party B can charge at its discretion. After the end of the warranty period, Party B is responsible for providing long-term maintenance services for Party A until Party A re-carries out the renovation project of the house.
Article 5 Agreement on production safety and fire prevention
1. The construction requirements provided by Party A shall be negotiated with Party B, and the construction site shall meet the requirements of fire prevention and accident prevention, mainly including electrical lines, gas pipelines, tap water and other pipelines. Party B shall take necessary safety protection and fire protection measures during the construction to ensure the safety of operators and adjacent residents, abide by the decoration guidelines of the property management department, and prevent accidents such as pipeline blockage, water leakage, power outage, and item damage in adjacent residents' houses. In case of the occurrence of the above circumstances, Party A shall be responsible for repairing and compensating for the above-mentioned circumstances. If it is the responsibility of Party B, Party B shall be responsible for repair and compensation.
2. Party B should pay attention to the safety of gas use, ensure the safety of climbing construction and other safety guarantees, and remind the construction personnel to pay attention to safety, this price includes safety fees, and all costs and responsibilities incurred in the construction caused by safety liability accidents shall be borne by Party B.
Article 6 on the project price and settlement agreement 1. Payment method for project payment:
23. Project settlement: (see Annex V "Project Settlement Statement").
Article 7 Liability for breach of contract
1. If the completion is overdue due to Party A's reasons, Party A shall pay Party B a penalty of 50 yuan for each overdue day after 15 days of overdue. If Party A fails to make the payment at the time agreed in the agreement, the overdue part shall pay interest to Party B at the current bank deposit interest rate for the same period during the overdue period.
2. If the completion is overdue due to Party B's reasons, Party B shall pay Party A a liquidated damages of 50 yuan for each overdue day after 15 days of overdue. 3. Party B shall be responsible for and bear the responsibility for any loss or accident (including fines) arising from the unauthorized demolition and alteration of the original load-bearing structure or shared equipment pipelines.
4. If the project fails to go through the acceptance and settlement procedures, and Party A uses the project in advance or uses the project without authorization, resulting in the inability to accept and loss, Party A shall be responsible.
5. If the key nodes of the project are not accepted, Party B shall be responsible for the next stage of project construction in advance, and Party B shall be responsible for the losses caused thereby.
6. If Party B fails to supply materials and equipment in accordance with the brand, specification, model and design and construction requirements specified in Annex II "Quotation of Contracted Materials", Party B shall compensate Party A twice according to the price of counterfeit and shoddy materials; If any loss is caused to Party A, Party B shall bear all the liability for compensation.
7. If during the construction process, there are problems with the quality of the project and materials and all kinds of responsibilities that should be borne by the construction team, Party A will only pursue the liability for compensation to Party B.
Article 8 Dispute Resolution
When there is a dispute between the two parties due to the quality of the project, the two parties should try to negotiate. or if the negotiation fails, it may apply to the Shanghai Arbitration Commission for arbitration or file a lawsuit with the people's court in accordance with this agreement
Article 9 Modification and Termination of Agreement
1. After the agreement is signed by both parties and takes effect, both parties must strictly abide by it. If either party needs to change the content of the agreement, it shall re-sign the supplementary terms after consensus.
2. During the construction process, either party proposes to terminate the agreement, it must be submitted in writing to the other party, and the liquidation procedures shall be completed with the consent of both parties, and the termination agreement shall be entered into to terminate the agreement.
3. If there is a quality problem due to Party B's construction, Party A can unconditionally propose to terminate the agreement without obtaining Party B's approval.
Article 10 Supplementary Provisions
1. Before the start of the project, Party A shall hand over the key to the exterior door of the house to the person in charge of the construction team of Party B for safekeeping. When the project is completed and accepted, Party A is responsible for providing 1_ sets of new locks, and Party B is responsible for installation and delivery on the spot. 2. After the signing of this agreement, the project shall not be subcontracted.
3. This Agreement shall be executed in 2 copies, one copy for each Party A and Party B, and the annex to the Agreement shall be an integral part of this Agreement and shall have the same legal effect.
Article 11 Annexes to the Agreement
Appendix 1: Decoration Guide of the Property Management Department Appendix 2: Quotation of Contracted Materials Appendix 3: List of Materials Purchased by Party A Appendix 4: Project Quality Acceptance Form Appendix 5: Project Settlement Appendix 6: List of Construction Processes
Party A (Signature): Party B (Signature): Address: Address:
Telephone: Telephone:
__________ ____Month____ ___________ ____ Month___
2024 Renovation Contract Sample Part 2
Party A: Party B:
Address: Address: No. 7, Jiangbin Road, Wuming District, Nanning City
Contact:Contact:
Service Rules:
1. Party A's housing survey service process:
1. Measurement of the customer's decoration house;
A. Wall structure analysis;
B. Analysis of light and air flow direction;
C. Water and potential analysis;
D. Dimensional measurement;
E. Analysis of the surrounding environment;
F. Take photos and record on site.
2. Functional analysis: Divide the reasonable use function according to Party A's living needs.
3. Style primary: choose the decoration style and category according to Party A's preferences.
4. Material research: the two parties will communicate and select the required materials.
5. Decorate the house and draw the floor plan:
A. Structural modification drawing;
B. Material drawing;
C. General layout plan;
D. Construction drawings.
2. Budget: According to the final communication between the two parties to determine the layout, decoration style and materials, the budget for the cost of the renovated house is proposed
3. Negotiation and exchange: Designer marketing personnel make an appointment according to Party A's time to exchange plans.
A. According to the standard Party A pays the deposit of ¥: RMB for the intention to cooperate, which will be included in the project payment after signing the formal decoration construction contract, and will not be charged separately.
B. If you have not signed this agreement and require the drawings or budget to be taken away, you must sign the design agreement and pay the corresponding design fee. (Design fee: 40 yuan/㎡)
4. Other matters:
A. If you are satisfied with the design plan and budget, you can sign a decoration construction contract with the company, in order to better serve you, the account manager will make an appointment with you in advance.
B, 3 days after the contract is signed on the construction site, there will be a technical disclosure work, the specific participants are, designers, project managers, construction team leaders, engineering supervisors, in order for you to be more clear about the project situation, please participate on time.
C. In the construction process, if you encounter engineering and technical problems, the project supervision will solve them for you in a timely manner, and if you encounter problems with the change of the design scheme, the designer of the project will serve you.
D. If you have any problems with our services, the marketing department will solve the problem for you as soon as possible, and your comments and suggestions are our greatest support and love.
D. If you understand and agree with the above service process, please sign this agreement of intent with the company when paying the measurement deposit, and we will strive to do better!
E. This Agreement shall be executed in duplicate by both parties, and will be terminated after the performance of this Agreement is completed
Note: In order to protect the relevant rights and interests of both parties, any oral agreement and commitment shall be deemed invalid, and all matters shall be based on this agreement of intent.
Party A : Party B :
Year-month-day: Year-month-day
2024 Renovation Contract Sample Part 3
Appointed by:
Contractor:
For the _____ decoration project, the two parties have signed this contract through friendly negotiation and jointly abide by the following:
First, the name of the project:
Second, the project location:
Third, the project content:
Fourth, the project period
The project was completed from ______, ______, ______ to ______, ______, ______.
5. The project cost is RMB: ____________________________________
6. Payment Methods
1. After the contract is signed, Party A's materials will arrive at the site, and Party A will pay Party B's total project advance payment for two days after the start of construction.
2. After the start of construction, Party A shall pay Party B the total amount of the project in advance according to the progress of the project to completion, and the balance shall be paid in a lump sum after the acceptance of the project. (Based on the unit price of the budget book, the settlement is based on the actual project quantity)
7. Materials and equipment: The engineering materials required for the project shall be procured by Party B, and the site shall be organized in a timely manner, and the materials and equipment shall be provided by Party A to meet the needs of the project and have a good storage place. The garbage and waste materials generated during the construction shall be cleaned up by the construction party.
8. Engineering construction
1. Party B must strictly follow the design drawings for construction, if there is a violation, Party A has the right to stop or rework, and Party B is responsible for the losses caused.
2. Party B is responsible for the decoration design, construction drawings and material details, after the approval of both parties, the information as an integral part of this contract, due to design defects caused by additional investment, and the design of the material plan is insufficient to increase the investment by Party B.
3. During the construction, Party A must notify Party B in advance of the addition and modification of the project, and both parties must sign an additional agreement, and Party A shall be responsible for the losses and lost work costs caused by the proposed addition and modification project to the construction, and the construction period shall be extended.
4. Party B shall understand and abide by the relevant regulations of the property management office, abide by the construction technical specifications, and the construction party shall be responsible for personal injury and damage to facilities caused by Party B's construction.
5. If Party B does not comply with the relevant regulations of the Property Management Office, Party B shall be responsible for the fine.
9. Project quality
1. The project is based on construction drawings, practice descriptions, and design changes as the quality assessment and acceptance standards.
2. Due to the unqualified quality of the materials provided by Party B and the quality of the project is affected, the rework cost shall be borne by Party B.
3. Party B shall be responsible for all the consequences of the quality accident that cannot be reworked due to the reasons of Party B.
4. One year warranty for the quality of decoration projects.
10. Project acceptance
Party B issued a notice of project acceptance, both sides of the personnel to the construction site, according to the design drawings and the relevant standards for the project acceptance, after acceptance, the person in charge of both sides should sign on the acceptance sheet to recognize, such as the project has not been accepted, Party A used in advance or unauthorized use, resulting in the quality, safety issues by Party A is responsible for the completion of the acceptance date and the date of Party A's start of use.
11. Liability for breach of contract
Any party who violates the terms of this contract shall be responsible for compensating the non-breaching party for any loss caused by the breach of this contract.
12. Remarks
If there are any uncertainties in this contract, Party A and Party B shall negotiate supplementary agreements or terms, such as this contract. In the event of a dispute between Party B, both parties have the right to submit arbitration or litigation to the Economic Contract Arbitration Commission or the People's Court of the Administration for Industry and Commerce where this contract is signed, and the arbitration or court judgment shall be executed according to the arbitration commission or court judgment.
13. The quotation form of this contract shall be in quadruplicate, and Party A and Party B shall each hold two copies, which shall take effect after being signed and sealed by the representatives of both parties, and shall have legal effect.
Party A unit (seal): ________
Representative: __________________
Party B unit (seal): ________
Representative: __________________
Date:____________________
Place of signing the contract: ____________
2024 Renovation Contract Sample Part 4
Contract No.: _________
Party A (Employer): ___
Company Name:_________
Address:_____________
NDC No.: _______
Mailing address: _________
Zip code:_________
Phone:_____________
Fax:_____________
Account:_____________
E-mail:_________
Party B (Contractor): ___
Qualification certificate number:_______
Legal address: _________
Legal representative:_______
Office:_____________
NDC No.: _______
Mailing address: _________
Zip code:_________
Contact:___________
Phone:_____________
Fax:_____________
Account:_____________
E-mail:_________
Article 1 Project Overview
1.1 Project location: Room _________, Building _________, No. _________, _________ Road, _________ District (County), _________ City.
1.2 Housing structure: _________ room type_________ rooms_________ halls _________ sets, construction area of _________ square meters.
1.3 Project cost: the price of the decoration project of the family room, according to the principle of market competition, high quality and high price, agreed as follows: total price: _________ yuan, capitalization (RMB): _________. Among them: material cost: _________, labor cost: _________, management fee: _________, design fee: _________, garbage removal freight: _________, tax: _________, other costs: _________. (See Appendix 3 for details: Quotation for family room decoration project). With the approval of both parties, the construction content will be changed, and the project cost of the changed part will be calculated separately.
1.4 Project contracting method: The two parties agree to adopt the following _________ methods.
(1) Party B contracts labor and all materials. (See Appendix 5: List of decoration materials provided by Party B)
(2) Party B contracts labor and part of the materials, and Party A provides some materials (see Annex 4: Party A provides a detailed list of decoration materials, Annex 5: Party B provides a detailed list of decoration materials);
(3) Party B contractor and Party A contractor all materials (see Annex 4: Party A provides a detailed list of decoration materials).
1.5 Project duration: _________ days; The commencement date is _________ _________ _________ and the completion date is _________ _________ _________
1.6 project content and practice (see Appendix 1: Decoration Engineering Construction Project Confirmation Form, Appendix 2: Decoration Engineering Content and Practice List).
Article 2 Qualifications of the construction unit
2.1 Any unit that undertakes the decoration and decoration project of the family room shall hold the "Construction Enterprise Qualification Certificate" issued by the construction administrative department with the scope of the construction decoration project.
2.2 Party B is an enterprise legal person approved and registered by the administrative authority for industry and commerce, and has passed the latest annual inspection of the enterprise, and has the qualification of engaging in civil building decoration and decoration projects approved by the competent administrative authority for construction, and the qualification level meets the requirements of this construction. If Party B does not have the business qualifications or corresponding qualifications, Party A has the right to terminate this contract, and Party B shall immediately return the fees paid by Party A and compensate for the losses.
2.3 For individual decoration practitioners who undertake family room decoration projects, they shall hold the work certificate, ID card, and temporary residence permit issued by the relevant competent departments of the people's governments above the township where they are located, and register with the construction administrative department or the agency designated by them where the project is located, and implement the system of "registration, training and assessment, skill appraisal, and holding a certificate". Specific measures shall be formulated by the construction administrative departments of the people's governments of provinces, autonomous regions and municipalities directly under the Central Government.
2.4 Where there is no "construction enterprise qualification certificate" or the construction administrative department issued by the individual decoration practitioner certificate of the unit and individual, shall not undertake the family room decoration project.
Article 3 Project supervision
If the project is supervised, Party A (or Party B) and the supervision company shall sign a separate "Project Supervision Contract", and notify Party B (or Party A) of the name, unit, contact information and responsibilities of the supervision engineer.
Article 4 Construction drawings
The two parties agreed that the construction drawings shall be provided in the following _________ ways:
4.1 Party A designs and provides construction drawings by itself, and the delivery time is _________ January _________, _________, and the drawings are in triplicate, and Party A, Party B, and the construction team each hold one copy. (See Annex VI: Home Decoration Engineering Design Drawings);
4.2 Party A entrusts Party B to design the construction drawings, the drawings are in triplicate, Party A, Party B, and the construction team each hold one copy (see Annex VI: Home Decoration Engineering Design Drawings), and the design fee is paid by Party A (this cost is not included in the project price);
4.3 The construction drawings shall come into force after being signed by both parties.
Article 5 Rights and Obligations of Party A
5.1 _________ days before the start of construction, create conditions for Party B to enter the construction. Vacate the house in whole or in part, and remove obstacles that affect the construction; Protective measures should be taken for the furniture and furnishings left in the house that can only be partially vacated, so as not to affect the construction. Party B's construction personnel shall carefully count and protect the livestock at Party A's construction site, and both parties shall sign a "list of items";
5.2 Dismantle the original telephone equipment before the start of construction; Provide water source and power supply during construction, and explain the precautions for use;
5.3 Responsible for coordinating the relationship between the construction team and the neighbors;
5.4 It is forbidden to dismantle the indoor load-bearing structure, and if it is necessary to dismantle or change the load-bearing and non-load-bearing structures of the building, or relocate the location of the kitchen and bathroom and the equipment pipeline, you should be responsible for going through the corresponding approval procedures with the relevant departments;
5.5 Participate in the supervision of project quality and construction progress, and the acceptance of materials entering the site and project completion;
5.6 The construction deposit and various property management fees collected by the property management department where the project is located shall be paid by Party A (except for the pass), and Party B shall assist in providing the relevant materials required for property management;
5.7 Party A shall not change the main body of the building and the load-bearing structure without the design plan proposed by the original design unit or the design unit with the corresponding qualification level;
5.8 Party A has no right to require Party B to move or renovate heating and gas pipelines;
5.9 The waste generated by the decoration of the house shall not be dumped indiscriminately, Party A shall be stacked in accordance with the location, method and time specified by the property management unit, the residents' committee where the house is located or the housing management department of the unit, and shall be removed and transported in accordance with the relevant regulations;
5.10 Party A shall not refuse or hinder the supervision and inspection of residential interior decoration activities by the property management unit in accordance with the provisions of the residential interior decoration management service agreement;
5.11 Party A shall not damage the original energy-saving facilities of the house and reduce the energy-saving effect when decorating;
5.12 Without approval, Party A shall not arbitrarily pierce holes in the load-bearing wall, remove the wall connecting the balcony doors and windows, expand the size of the original doors and windows, or build new doors and windows; It is not allowed to increase the static load of the floor at will, build walls or overload ceilings indoors, install large lamps and ceiling fans; The roof shall not be arbitrarily chiseled, and the wires shall not be directly buried or rerouted without passing through the pipe;
5.13 Without approval, Party A shall not damage public facilities such as water supply and drainage, power supply, gas supply, fire protection, communications, etc., and shall not damage other people's houses and belongings.
5.14 Party A shall be responsible for repairing and compensating for the blockage, water leakage, power outage, and damage to the adjacent residents' houses caused by the decoration and decoration of the family room. If it is the responsibility of Party B, Party A shall be responsible for repairing and compensating Party B.
Article 6 Party B's Rights and Obligations
6.1 During the construction, the national "Residential Decoration and Decoration Engineering Construction Code" shall be strictly implemented to ensure the quality of the project and complete the project on schedule;
6.2 Units and individuals undertaking family room decoration projects shall take necessary safety protection and fire protection measures to ensure the safety of workers and adjacent residents;
6.3 Protect the furniture and furnishings in the original room, and ensure the smooth flow of the upper and lower pipes in the living room;
6.4 All kinds of waste formed by the decoration of the family room shall be stacked and removed in accordance with the location, method and time designated by the relevant departments. It is strictly forbidden to throw away the waste and other items generated by the decoration of the living room from the upper floor to the ground or from the garbage chute or sewer;
6.5 Party B's designer is responsible for providing Party A with consulting, design, quotation and other related services. After the contract is signed, the representative of Party B to carry out the construction of the project is the project manager sent by Party B. Party A shall contact Party B's project manager on all matters related to the project to ensure unified command and management in the project;
6.6 If Party B purchases or recommends to Party A to use decoration materials that do not meet national standards, causing air pollution exceeding the standard and causing losses, Party B shall be liable for compensation according to law;
6.7 The decoration materials used by Party B shall not be shoddy or fraudulent.
6.8 Party B's construction shall comply with the requirements of relevant specifications, and shall not cut corners or make shoddy work;
6.9 Party B shall not carry out barbaric construction and endanger the safety of the building itself;
6.10 Party B shall not deceive the market or force transactions;
6.11 Party B shall not fraudulently use other enterprise names and trademarks;
6.12 Party B shall not harm the rights and interests of residents and other business operators;
6.13 In the area where residents live, between 12:30 and 14:30 and 19:30 and 19 and 7 the next day, Party B shall not engage in house decoration activities that cause noise.
Article 7 Project Change
7.1 In order to ensure the quality, duration and warranty service of Party A's project, if there is any change in the project or construction method after the contract is signed, the two parties shall sign a written agreement "Decoration Project Change Order" (see Annex VII: Home Decoration Project Change Order) after negotiation, and at the same time adjust the relevant project costs and construction period, and the oral commitment or oral agreement shall be deemed invalid; Party A shall bear all the consequences caused by the change of construction content directly agreed with Party B's on-site staff;
7.2 After the contract is signed, when the reduction of Party A's project exceeds 5% of the total project cost, Party B shall pay a change fee of 8% of the total reduction amount. If Party B has ordered or shipped the materials used by Party A to the site, Party A shall pay for the cost of consignment, loss and return of materials; If the construction project requested by Party A has been constructed, Party A shall pay Party B the construction fee, material cost, management fee and demolition fee of the project;
7.3 For the construction of the increase after Party A pays the project price for the second time, Party B shall carry out the construction only after receiving 100% of the project payment from Party A.
Article 8 Provision of Materials
8.1 The specifications and quality of the materials and equipment provided by Party A shall meet the design requirements (see Annex 4: Party A provides a detailed list of decoration materials). Party A shall transport the materials and equipment to the construction site on time and notify Party B, and the two parties shall jointly accept and handle the handover procedures; If Party A fails to provide materials on time or the specifications and quality of the materials do not meet the design requirements, thereby delaying the construction period or affecting the quality of the project, Party A shall bear the responsibility;
8.2 For the materials and equipment provided by Party B (see Annex 5: Party B provides a detailed list of decoration materials), Party B shall notify Party A in advance of the time when the materials and equipment are transported to the construction site, and both parties shall jointly accept the goods; If the brand, specification and quality of the materials supplied by Party B are inconsistent with the quotation, Party A has the right to refuse to use them, thereby delaying the construction period or affecting the quality of the project, and the responsibility shall be borne by Party B;
8.3 Party A determines the brand, specification, model or price standard of the material, and Party B is responsible for purchasing it for Party A (see Annex 4: Party A provides a detailed list of decoration materials.) It should be noted that Party B purchases on behalf of Party B), and the materials can only be used after being transported to the construction site and accepted by Party A. Party B charges Party A's material purchasing fee as the material procurement and management fee (_________% of the material price) + material transportation fee (determined according to the actual situation); If the return and replacement caused by material quality problems during the construction process, as well as the delay in the construction period, Party A shall be responsible;
8.4 Except as specified in the contract, hardware (door locks, handles, faucets, etc.), stones, tiles, equipment, sanitary ware, lamps, etc., shall be purchased by Party A and delivered to the site on time; If Party B needs to purchase on behalf of Party B, _________% of the purchase cost and transportation fee of the purchased materials will be charged.
Article 9 Delay in construction period
9.1 If the completion date is delayed due to the following reasons, the construction period shall be extended accordingly upon confirmation by Party A:
(1) Quantity change and design change;
(2) force majeure;
(3) Stoppage caused by Party A's failure to participate in the stage acceptance on time;
(4) Other circumstances in which Party A agrees to the extension of the construction period.
9.2 If the construction period is affected due to Party A's failure to complete the work for which it is responsible as agreed, the construction period shall be extended; If the quality of the project is affected due to the unqualified quality of the materials and equipment provided by Party A, the rework cost shall be borne by Party A, and the construction period shall be extended;
9.3 If Party A fails to pay the project price on time, the contract period shall be extended accordingly;
9.4 If the project cannot be completed on time due to Party B's supply of materials or construction, the construction period will not be extended; If there is a problem with the quality of the project due to Party B's reasons, the rework cost shall be borne by Party B, and the construction period will not be extended.
Article 10 Quality Standards
10.1 Quality of Works
(1) Party B must carry out construction in accordance with the design documents and the current national technical standards and specifications.
(2) The projects contracted by Party B must all meet the current national project quality acceptance standards, and the first-time acceptance pass rate of the project must reach 100%, and the excellent rate must reach _________.
(3) For any project with unqualified construction quality caused by Party B, Party B shall rework it free of charge within the time specified by Party A to meet the project quality acceptance standards. If it still cannot be reached after rework, Party B shall bear the liability for breach of contract. If the project quality standards cannot be met due to Party A's reasons, Party A shall bear the responsibility for rework and economic expenditure.
10.2 The two parties agree that the construction quality of the project shall be accepted according to the following _________ standards:
(1) "GB50210-Code for Quality Acceptance of Building Decoration and Decoration Engineering"
(2) "Regulations on the Quality Acceptance of Family Housing Decoration and Decoration Projects in _________ City"
(3) Other acceptance criteria: _________
10.3 In the event of a dispute between the two parties over the quality of the project during the construction process:
(1) You can complain to the _________ Consumer Association Home Decoration Complaint Center or _________ Building Decoration Association for mediation;
(2) If you are not satisfied with the mediation, the engineering quality inspection agency agreed by both parties shall appraise the required costs and the losses caused thereby, and the responsible party shall bear the costs. The responsibilities of both parties shall be borne separately by each party according to their respective responsibilities.
Article 11 Project acceptance and warranty
11.1 The two parties agree to accept the quality of the project in the following three stages during the construction process:
(1) Acceptance of concealed projects such as water and electricity pipelines, waterproof layers and ceiling bases;
(2) Pre-construction acceptance of paint and surface coating;
(3) Completion acceptance. Party B shall notify Party A two days in advance to carry out the acceptance of each stage, and shall fill in the project acceptance form after passing the acceptance of each stage (see Annex VIII: Project Acceptance Form). If Party A fails to participate in the acceptance on time after receiving the notice, Party B has the right to stop work and wait, and the delay and other losses caused to Party B shall be borne by Party A;
11.2 Maintenance
(1) After the completion and acceptance of the project and the balance of the project is settled, Party B shall go through the handover procedures to Party A (see Annex 9: Project Settlement Statement) and fill in the project warranty form (the warranty period is two years) (see Annex 10: Project Warranty Sheet).
(2) Under normal use conditions, the minimum warranty period for residential interior decoration and decoration projects is two years, and the leakage prevention of kitchens, bathrooms and exterior walls with waterproof requirements is five years. The warranty period is calculated from the date of completion and acceptance of the residential interior decoration project.
Article 12 payment method of project payment
12.1 The parties agree to pay for the project in the following _________ ways:
(1) After the signing of this contract, from _________ to _________ days before the start of construction, Party A shall pay the project payment equivalent to _________% of the total price;
(2) Within _________ days after the date of completion of _________% of the project quantity, Party A shall pay the project payment equivalent to _________% of the total price;
(3) Within _________ days after the completion and acceptance, Party A shall pay the project payment equivalent to _________% of the total price.
(4) After _________ years after the completion and acceptance or the expiration of the warranty period agreed by both parties, Party A shall pay the project payment equivalent to _________% of the total price.
If Party A pays the project money and Party B's salesman or construction personnel collects it, it shall be deemed to be collected by Party B.
12.2 If the total price increases or decreases due to the change of construction content, Party A shall pay or receive the increase or decrease on the date of completion and acceptance.
12.3 Receipts shall be issued for both parties. After the construction is completed, Party A shall issue a legal invoice after Party A pays the payment in full.
12.4 After the completion and acceptance are qualified, Party A has the right to retain the warranty fund equivalent to _________% of the total price of the project. If there is no project quality problem within _________ years after the completion and acceptance, Party A shall return the warranty fund to Party B in full.
Article 13 Liability for breach of contract
13.1 After the contract is signed, if either party to the contract proposes to terminate the contract or breach the contract for any reason, resulting in the inability to perform the contract, it shall notify the other party in a timely manner, and after consultation and agreement between the two parties, it may go through the procedures for terminating or postponing the performance of the contract, and the breaching party shall pay liquidated damages equal to _________% of the project cost to the non-breaching party; If the loss is caused as a result, the breaching party shall compensate for it.
13.2 If the project is not accepted or the balance payment is not handed over, and Party A uses or uses the finished product of the project without authorization, the project shall be deemed to be qualified, and Party A shall be responsible for the losses caused thereby, and Party A shall be deemed to have automatically waived the warranty and maintenance rights and Party B still has the right to recover the balance payment.
13.3 If Party A fails to pay the project payment on time, Party B has the right to stop the work and pay Party B a liquidated damages of 2‰ of the total project cost for each day of delay.
13.4 If the quality of the project does not meet the quality standards agreed by both parties due to Party B's reasons, Party B shall be responsible for repairing the project, and the required repair costs shall be borne by Party B, and the construction period shall not be extended.
13.5 If the construction period is delayed due to the reasons of Party A or Party B, the responsible party shall pay 2‰ of the total project cost to the other party as liquidated damages for each day of delay.
Article 14 Settlement of Contract Disputes
In the event that the dispute between the two parties cannot be resolved through negotiation, it shall be resolved in the following _________ manner:
14.1 Apply to the _________ Arbitration Commission for arbitration;
14.2 Filing a lawsuit with the people's court.
Article 15 Other specific provisions
15.1 For decoration projects outside the urban area of _________, Party B shall charge an additional remote construction fee of 3%-10% of the total cost of the project;
15.2 Party B shall be responsible for the removal and transportation of the garbage generated due to the construction of the project to the garbage dumping point specified by the government, and Party A shall pay the garbage removal fee (RMB) _________ yuan (this cost is not included in the project payment);
15.3 During the construction period, Party A shall hand over the outhouse door key _________ to the person in charge of Party B_________ who shall be responsible for safekeeping. After the completion and handover of the project, Party A is responsible for providing new locks and _________, and Party B is responsible for installing them on the spot and delivering them to Party A for use;
15.4 During the construction period, Party B's working hours are from _________:_________ a.m. to _________:_________ a.m. every day; _________:_________ p.m. to _________:_________ p.m.
Article 16 Supplementary Provisions
16.1 The works shall not be subcontracted after the signing of this contract.
16.2 If both parties directly sign the contract, this contract shall be signed (sealed) by both parties in duplicate, and each party shall hold one copy.
16.3 Where the contract is signed in the home decoration and decoration market in _________ City, this contract shall be in triplicate, and it shall come into force after being signed (sealed) by both parties A and B and the relevant departments of the market, and each of the three parties shall hold one copy.
16.4 Termination of the Contract upon completion of performance.
16.5 This contract implements voluntary verification by the parties to protect the legitimate rights and interests of the parties to the contract.
16.6 The annexes to the contract are an integral part of this contract and have the same legal effect as this contract.
Article 17 Interpretation of Contract
If the matters not covered in this contract or the content of the terms are not clear, the parties to the contract can make a reasonable interpretation of this contract according to the principles of this contract, the purpose of the contract, the transaction customs and the content of the related clauses, according to the common understanding. This interpretation shall be binding unless it contravenes the law or this contract.
Party A (Signature): ____________ Party B (Seal): _________
Legal Representative (Signature): ______ Authorized Agent (Signature): ___
Place of Signing: ________________ Place of Signing: _____________
_______/______/_______ _______________
Home Decoration Market Contract Certification Opinion (Shopping Mall Contract Certification Seal): _________
Authorized Agent (Signature): ______
Contact number: ________________
Place of Signing: ________________
_______/_____________
2024 Renovation Contract Sample Part 5
Employer (hereinafter referred to as Party A): Contractor (hereinafter referred to as Party B):
Entrusted Agent: Construction Leader:
Phone: Phone:
In accordance with the provisions of the Contract Law of the People's Republic of China and relevant laws and regulations, combined with the characteristics of the construction of the family room decoration project, the two parties have reached the following agreement on the relevant matters of Party A's family room decoration project (hereinafter referred to as the project) on the basis of equality, voluntariness and consensus:
Article 1 Project Overview
1.1 Project location:
1.2 Project content and practices (see Appendix 1 for details: quotation and construction drawings of family room decoration project).
(1) Party B's contracted labor and materials;
(2) Party B contracts labor and part of the materials, and Party A provides part of the materials;
(3) Party B's contractor and Party A's contractor.
1.4 The duration of the project is working days, the start date is the year, the month and the completion date is the first working day.
1.5 Contract price: The project cost of this contract is (RMB capitalization): (¥).
1.6 The purchase price of the main material is (capitalized RMB)
Article 2 Construction drawings
The parties agreed that the construction drawings shall be provided in the following second ways:
(1) Party A designs and provides construction drawings by itself;
(2) Party A entrusts Party B to design construction drawings.
Article 3 Party A's Obligations
3.1 Three days before the start of construction, create conditions for Party B to enter the construction. Including: removing the indoor furniture and furnishings or piling up and covering the furniture and furnishings that are not easy to move indoors, so as not to affect the construction.
3.2 Provide water source and power supply during construction.
3.3 Responsible for coordinating the relationship between the construction team and the neighborhood.
3.4 Do not dismantle the indoor load-bearing structure, if you need to dismantle the non-load-bearing structure or equipment pipeline of the original building, you are responsible for going to the relevant departments for the corresponding approval
3.5 Responsible for handling the commencement procedures of the property management company, and bear the various expenses of the property management company (no matter what name), caused by Party B's construction reasons
3.6 During the construction period, if Party A still needs to partially use the living room, it shall be responsible for the security and fire protection of the construction site.
3.7 Participate in the supervision of project quality and construction progress, material acceptance and completion acceptance.
3.8 Pay according to the time agreed in the contract, otherwise Party A shall be responsible for the delay and related costs caused by the construction period.
Article 4 Party B's Obligations
4.1 Strictly implement the safety construction operation specifications, fire prevention regulations, construction specifications and quality standards during the construction, and complete the project on time and with good quality.
4.2 Strictly implement the regulations on the management of the construction site, and shall not disturb the people and pollute the environment.
4.3 Protect the furniture and furnishings in the original room, and ensure that the upper and lower water pipes in the living room are unblocked.
4.4 Ensure the cleanliness of the construction site, and be responsible for cleaning the construction site after the completion of the project. If the cost of cleaning is included in the budget, you will also be responsible for 1 professional cleaning
Article 5 Project Change
5.1 If the project and construction method need to be changed, the two parties shall reach a consensus and sign the "Project Change Order", and adjust the relevant project costs and construction period
5.2 The project change shall be jointly agreed upon and signed by Party A, Party B's designer and construction administrator.
5.3 During the construction, all the consequences caused by the changes made by Party A and Party B's construction personnel (including foremen and workers) in violation of the treaty shall be borne by Party A
5.4 After the contract is signed, if either party A or Party B requests to reduce the items specified in the contract, it shall be a partial breach of contract and shall pay the reduction fee to the other party
Article 6 Provision of Materials
6.1 For the materials and equipment provided by Party A, Party A shall notify Party B before the materials are transported to the construction site, and both parties shall jointly accept and handle the handover procedures.
6.2 For the materials and equipment provided by Party B, Party B shall notify Party A before the materials are transported to the construction site and accept Party A's inspection.
Article 7 Delay in construction
7.1 If the completion date is delayed due to the following reasons, the construction period shall be extended accordingly upon confirmation by Party A:
(1) Quantity change and design change;
(2) force majeure;
(3) Other circumstances in which Party A agrees to extend the construction period.
7.2 If the construction period is affected due to the completion of the work for which Party A is responsible as agreed, the construction period shall be extended; Due to the unqualified quality of materials and equipment provided by Party A
7.3 If Party A fails to pay the project payment on time, the contract period shall be extended accordingly.
7.4 If the construction period is affected due to Party B's failure to start work on time or stop work without reason, the construction period will not be extended; The quality of the project exists due to the reasons of Party B
7.5 If the delay in the supply of materials by Party A or the occurrence of quality differences such as specification differences, Party A shall undertake the delay.
Article 8 Quality Standards
The two parties agree on the construction quality standards of the project, and perform them according to the contract between the two parties.
During the construction process, the two parties have a dispute over the quality of the project, and the quality inspection department certifies the quality of the project, and the quality of the certified project does not match
Article 9 Project acceptance and warranty
9.1 The two parties agree to accept the quality of the project in the following stages during the construction process:
(1) Completion of concealed works;
(2) Completion of the mud project;
(3) Completion of woodworking and painting works.
Party B shall notify Party A two days in advance for acceptance, and the next process can only be done after passing the stage acceptance.
9.2 After the completion of the project, Party B shall notify Party A of the acceptance, and Party A shall organize the acceptance within two days after receiving the acceptance notice. After the project payment is settled, it will be done
Article 10 payment method for the project
10.1 The parties agree to pay for the works in the following manner (1):
(1) After the contract comes into effect, Party A shall pay the project payment directly to Party B as agreed in the following table:
(2) Payment method: (1) (transfer card) card number: Account name: Bank: CCB.
Payment method: (2) Party A shall pay Party B in cash for each phase of the project, and Party B shall issue a receipt as a valid payment voucher. If Party A will pay for the project
Party B shall not assume any responsibility for any problems caused by errors and losses caused by the transfer of funds to persons other than Party B.
10.2 After the acceptance of the project, Party B shall propose the project settlement to Party A, and send the relevant information to Party A, and the two parties shall verify and determine the total construction of the project
Article 11 Other Matters needing attention
11.1 Since the quantity of hydropower renovation cannot be accurately budgeted in the budget stage, it is only estimated, which may have a certain deviation from the actual quantity, so the settlement is subject to the actual quantity.
11.2 The garbage removal freight in the budget table refers to the garbage transported from the construction site to the garbage dumping point in the residential area designated by the property, and the cost incurred does not include the cost of external transportation.
11.3 The cleaning fee in the Budget Table refers to a professional company cleaning after the completion of the project. If Party A carries out other project construction after cleaning, Party B is not responsible for cleaning again.
11.4 Party B shall not be liable for the delay of the construction period and the protection of the finished product if the cross construction is caused by Party A entrusting others to engage in other construction projects without authorization. 11.5 The completion of the project means that Party B has completed the construction of all the charging items on the "Budget Table" and the "Project Change Order", and other construction projects organized by Party A are not within the scope of Party B's construction responsibility.
11.6 Party B shall not be liable for any fees (regardless of name or reason) stipulated by the property of the community.
11.7 All construction projects for which Party B is responsible shall be based on the construction drawings signed and agreed by Party A, if Party A needs to modify the drawings during construction, Party B shall agree to the designer and sign the project change order before construction, and shall not modify the plan for any reason. Party A shall be responsible for any increase or loss of expenses caused thereby.
Article 12 Liability for breach of contract
12.1 If either of the parties to the contract is fined or causes losses to the other party due to failure to perform the contract or violation of national laws, regulations and relevant policies, the responsible party shall be liable and compensate the other party for the economic losses caused.
12.2 Party A shall be responsible for the loss caused by Party A's use in advance or unauthorized use of the finished product without going through the acceptance procedures, as well as the damage to the finished product when Party A entrusts other construction teams to construct the project.
12.3 If the contract cannot be continued due to the reasons of one party, the other party shall notify the other party in a timely manner, go through the procedures for terminating the contract, and the responsible party shall compensate the other party for the corresponding economic losses.
12.4 If Party A fails to pay the second (third) project payment on time, it shall pay liquidated damages of RMB 20 to the other party for each day of delay.
12.5 If the quality of the project does not meet the quality standards agreed by both parties due to the reasons of Party B, Party B shall be responsible for repairing the project and the construction period shall not be extended.
12.6 If the construction period is delayed due to Party B's reasons, the other party shall be paid a penalty of RMB 20 for each day of delay.
Article 13: Miscellaneous
13.1 The settlement shall be subject to the budget unit price, and the measured quantity of both parties shall be the settlement of the project quantity.
13.2 If there is an additional project during the construction process, the visa negotiated by both parties shall prevail.
13.3 During the construction process, if Party A's reduction exceeds 5% of the total budgeted cost, all discounts will be cancelled and liquidated damages will be paid at 20% of the reduced project (except for force majeure factors).
13.4 In the settlement, Party A shall not increase the total cost of the settlement without increasing the project, and Party B shall be responsible for any other than 5% (hydropower projects are not included in this agreement).
13.5 From the date of completion and acceptance, if the balance is not settled with Party B within 15 days, all discounts will be halved, and if the balance is not settled with Party B within 30 days, all discounts will be cancelled and a late fee of 0.5‰ will be paid every day.
13.6 Any payment of Party A shall be handed over to Party B, and Party B shall issue an official receipt or invoice, and Party A shall not hand over the payment to other personnel of Party B without authorization, otherwise Party B shall not be responsible for any losses caused thereby.
Article 14 Settlement of Contract Disputes
Disputes arising from the performance of this contract shall be resolved through negotiation between the parties; It is also mediated by the relevant authorities; If negotiation or mediation fails, it shall be resolved in the following ways:
(1) Submit to the Consumer Arbitration Commission for arbitration;
(2) Initiate litigation in the people's courts in accordance with law.
Article 15 Several specific provisions
15.1 Party B is responsible for transporting the garbage out of the construction site and transporting the garbage to the designated place, and Party A is responsible for paying the garbage removal fee (capitalized) yuan.
15.2 During the construction period, Party B's daily working hours are: from a.m. to a.m.; From ______ p.m. to p.m.
Article 16 Other Agreed Matters:
Article 17 Supplementary Provisions
16.1 This contract shall come into force after being signed (sealed) by both parties and shall be terminated upon the completion of the performance of the contract.
16.2 The works shall not be subcontracted after the signing of this contract.
16.3 Joint Bundle
16.4 The annexes to the contract are an integral part of this contract and have the same legal effect as this contract.
Annexes to the contract
Appendix 1: Quotation for family room decoration and decoration projects
Appendix 2: Design drawings of family room decoration and decoration projects
Party A (Signature): Party B (Signature):
Year-Month-Month-Day
2024 Renovation Contract Sample Chapter 6
Kokata:
Address: Telephone:
Party B:
Address: Telephone:
Now Party A has three model rooms, located in the fifth phase of the garden of Dongsheng Town, XX City, contracted to Party B for decoration, and the agreement is signed as follows:
1. The content, scope, method, time and quality of the contracted decoration project
1. Content scope: The content scope of the project includes: indoor ceiling, ground mud paving, composite flooring, doors, wardrobes, TV cabinets, wall oil paint, indoor supporting facilities, etc. (See the interior decoration budget table for details)
2. Contracting method: Party B contracts labor and materials, and the water and electricity used for decoration are borne by B.
3. Project completion time: xx year xx month xx day.
4. Project quality: according to the national building decoration standards.
2. Party B's Responsibilities:
1. Due to Party A's short requirements for the decoration project, in order to ensure that Party A's decoration is completed on time, Party B must complete all the projects before xx year and xx month.
2. After the completion of the project, after the on-site acceptance of both parties, if it does not meet the requirements of the project, Party B shall be responsible for the materials and costs of all unqualified projects and rework.
3. Party B shall be responsible for all safety accidents that occur during the installation and decoration of Party B, and Party A shall not be responsible for any responsibility.
3. The total value of this contract is RMB: 149,500 yuan, capitalized: one hundred thousand thousand Wu Bai yuan. (Package invoicing)
Thereinto:
1. The interior decoration cost of Room 204, Block B, Building 29: 37,500 yuan
2. The interior decoration cost of Room 201, Block B, Building 29: 46,000 yuan
3. The interior decoration cost of Room 203, Block A, Building 29: 66,000 yuan
Fourth, the contract settlement uses the uniform invoice of the tax bureau.
5. Payment Methods:
After the completion of the acceptance of Party A, the project will pay 50%, that is, 75,000 yuan, and the remaining 50%, that is, 74,500 yuan, and pay off the project after the model house is sold and the owner accepts it.
6. Warranty service:
Party B provides warranty services to Party A and the owner, and the warranty period is three years. (Calculated from the sale of Party A and the acceptance of the owner), Party A shall designate a special person or property management department to contact Party B.
7. This Agreement shall be executed in duplicate and shall come into force after being signed by both parties. During the implementation of this agreement, if there are any unfinished matters, it can be resolved through negotiation.
Party A: XX City XX Real Estate Development Co., Ltd
(stamped)
Party B: Decoration Engineering Department of Dongsheng Town, XX City
(stamped)
xx/xx/xx